Contract - offer
for provision of consulting services during construction works
1. General Provisions
1.1 This public agreement (hereinafter - "Offer" or "Agreement") is a formal offer of Karbonit Limited Liability Company (Karbonit LLC) hereinafter referred to as "Contractor", to conduct a cycle of consulting activities, in the course of construction and repair work at the site of individuals recognised as "Customers" in accordance with the terms of this Offer.
1.2. . In accordance with paragraph 3 of Article 438 of the Civil Code of the Russian Federation (hereinafter - the Civil Code of the Russian Federation), in the case of acceptance of the conditions set out below and payment for services, the individual or legal entity making acceptance of this offer, becomes the Customer, and the Contractor and the Customer together - the Parties to the offer agreement.
1.3 By performing actions on acceptance of this public offer agreement, the Customer confirms his legal capacity and legal capacity, as well as the legal right of the Customer to enter into contractual relations with the Contractor.
2 Terms and definitions
2.1 For the purposes of this Offer the following terms are used with the following meaning:
- Offer Agreement - an agreement between the Contractor and the Customer for the performance of work, provision of services, which is concluded by means of acceptance of the Offer.
- Customer - the User, who has made an acceptance of the Offer, and is thus the Customer of the Contractor's services under the concluded Offer Agreement.
- Contractor - a person providing services under the Offer Agreement: LLC "Carbonit".
- Website - Website https://karbonit.pro/, where the Offer is placed.
- Service - a cycle of consulting activities in the process of construction and repair works at the Customer's site.
- Acceptance of the Offer - full and unconditional acceptance of this public Offer by taking actions to receive the Service and making its payment in cashless form to the details of the Contractor specified on the Site.
3. Subject of the Offer
3.1 The Contractor undertakes to carry out a cycle of consulting activities, in the course of construction and repair works at the Customer's site, and the Customer accepts and pays for construction consulting services in the course of construction works under the terms of the Agreement.
3.2 The Contractor undertakes to organise:
- One-off visit of the engineer.
- Preliminary analysis of design and executive documentation, acts of completed works, photo and video archive, collection of data from the developer or owner.
- Analysis of the correct selection of the wall construction and its insulation, with the help of thermal calculation.
- Analysing the strength of concrete structures by non-destructive method, using certified equipment.
- Analysing the quality of the building envelope (walls, roofing, window and door elements), checking the house contour for heat loss using a thermal imaging camera.
- Analysing the quality of finishing works.
- Checking the operation of water and drainage systems, waterproofing measures.
- Analysing the laying and commissioning of engineering networks.
- Analysis of the device of engineering equipment, electrical systems, water supply and heating systems, as well as the sewerage system.
- Analysis of the façade system, wet façade, stone façade, other façade design.
3.3 The works on the quality of implementation of the construction object, are carried out in accordance with the requirements of the organisation of construction works of the Russian Federation.
3.4 The Contractor undertakes to carry out the works specified in clause 3.1 of the Contract using its own resources and means, in accordance with the established procedure and within the time limits specified in the Contract.
3.5 When rendering services, the Contractor has the right to engage auditing organisations or auditors, consultants, and other specialists in the field of construction control and other expertise on the basis of a civil law contract. In this case the Contractor shall be liable to the Customer under this contract.
4. Contract price and settlement procedure
4.1 The cost of the construction control service is 50 000 (fifty thousand) roubles, without VAT, as the Contractor applies the simplified taxation system.
4.2 Payment for the Services is made by the Customer by transferring money to the Executor's settlement account according to the details specified in the Contract.
4.3 Payment for the services is made within 3 (three) banking days from the moment of the Executor's invoice, in the amount of 100 % of the cost of services under the Agreement on the basis of the invoice issued by the Executor.
4.4 The date of payment is the date of crediting the funds to the Executor's settlement account.
5. Terms of service provision
5.1 The term of service rendering is 3 (three) working days from the moment of crediting the funds to the Executor's settlement account.
6. Rights and obligations of the Customer
6.1 The Customer is obliged:
6.1.1 Provide the Contractor with access to the object and to the working documentation.
6.1.2 Observe confidentiality of the information, which became known to the Customer within the framework of this Contract.


6.1.3 Before the beginning of the services rendering provide the Contractor with the existing technical documentation on the object, necessary for the performance of the services, if possible in electronic form, if any.
6.1.4. Assist the Contractor in the performance of services under this Agreement, within three calendar days to coordinate the requests, enquiries, documents necessary for the performance of services received from the Contractor electronically, via messengers.
6.1.5 Provide access of the Contractor's representatives to the object for performance of services during the whole period of performance of services under the present Contract. If access to the object requires a special pass (certificate, other authorisation document), the Customer undertakes to provide the Contractor's representatives with a special pass to the object by the moment of the beginning of rendering the services under the present Agreement and for each day of the visit to the object;
6.1.6 Accept the rendered services according to the report formed by the Contractor or his representative during the work process.
6.1.7. At the Contractor's request, within three calendar days, to provide additional initial data necessary for the performance of works on rendering services.
6.1.8 The Customer undertakes to comply with the terms and conditions of this Contract-Offer.
6.2 The Customer has the right:
6.2.1. To check at any time the progress and quality of service provision.
7. Rights and obligations of the Contractor
7.1 The Contractor is obliged to:
7.1.1 Appoint a responsible Supervisory Contractor and ensure his presence at the site, with the Contractor being responsible to the Client.
7.2 The contractor shall:
7.2.1 Inspect the construction and installation work performed and in progress. To assess the quality of the materials used, their installation and arrangement in accordance with the design documentation.
7.2.2 Evaluate the quality of execution of the load-bearing structures of the house, foundation, walls, flooring, roofing.
7.2.3 Assess the quality of exterior and interior finishes.
7.2.4 Assess the quality of installation of engineering systems, heating, water supply, electrical and low-current systems, sewerage system, ventilation system.
7.2.5. To issue remarks and recommendations in the report to the Customer on elimination of revealed violations and deviations from the design documentation.
7.2.6 Prepare a report and summary on the general technical condition of the object. 7.2.7.
7.2.7 The Contractor undertakes to carry out the work specified in clause 1.1. with due diligence, at a high level and hand over the results to the Customer.
8. Liability of the parties and force majeure
8.1 The parties shall be liable for failure to fulfil the terms and conditions of this Contract in accordance with the current legislation of the Russian Federation or any other country where the work is performed.
8.2 In case of the Customer's delay in fulfilment of the obligations stipulated by the Contract, the Contractor shall be entitled to demand payment of a penalty. The penalty shall be charged for each day of delay in fulfilment of the obligations stipulated by the Contract, starting from the day following the day of expiry of the time limit for fulfilment of the obligations stipulated by the Contract. The amount of such penalty shall be set at the rate of one per cent of the Contract price.
8.3 In case of delay in fulfilment of obligations stipulated in the Contract by the Contractor, the Customer shall have the right to demand payment of a forfeit. The penalty shall be charged for each day of delay in fulfilment of the obligations stipulated by the Contract, starting from the day following the day of expiry of the term for fulfilment of the obligations stipulated by the Contract. The amount of such penalty shall be set at the rate of one three hundredth of the refinancing rate of the Central Bank of the Russian Federation effective on the date of payment of the penalty.
The Contractor shall be exempt from payment of the penalty if it proves that the delay in fulfilment of the said obligation has occurred due to force majeure or due to the Customer's fault.
8.4 The Contractor shall not be liable for breach of the terms of the Offer Agreement if such breach is caused by force majeure, including, but not limited to: actions of public authorities, fire, flood, earthquake, other acts of God, lack of electricity and/or computer network failures, strikes, civil unrest, riots, actions (inaction) of the building administration, preventing the Contractor from accessing the premises, any other circumstances that may affect the Contractor's access to the premises, any other circumstances that may affect the Contractor's access to the premises.
8.5 The Contractor's aggregate liability under the Offer Agreement, for any claim or claim in respect of the Offer Agreement or its performance, shall be limited to the value of the services/works for which the Customer has a claim.
9. Cancellation and suspension of the Contract

9.1 The Contractor shall have the right to refuse to fulfil the Contract according to Article 782 of the Civil Code of the Russian Federation, notifying the Client 5 (five) days in advance, and to claim compensation for damages if the Client's breach of his obligations under the Contract, in particular failure to provide the necessary documentation and other obligations stipulated by the Contractor, prevents the Contractor from fulfilling the Contract.
9.2 The Customer may refuse to fulfil this Contract by notifying the Contractor 5 (five) days in advance with justification of the reasons for the refusal. In this case the Customer shall be obliged to pay to the Contractor the full amount of actually incurred expenses as of the date of the written cancellation of the execution of this Agreement.
9.3 If the performance of services is stopped by the Contractor through his fault, the Customer shall not pay the Contractor's additional expenses related to such suspension.
9.4 If the performance of services is stopped by the Customer through his fault, the amount of prepayment shall not be returned to the Customer.
10. Other conditions
10.1 The Parties guarantee confidentiality of documents, terms and conditions of the contract and the cost of work performance.
10.2 Fragments of the work process may be demonstrated in social networks of either party, but shall not be of compromising nature and shall not contribute to undermining the reputation of either party.
10.3 This Contract is made in two copies in Russian language, having equal legal force, one copy for each of the Parties.
10.4 All appendices, amendments and additions to this Agreement shall be valid only if they are executed in writing and signed by both Parties (may be scanned and sent electronically). 10.5. All appendices, amendments and additions to this Agreement shall be valid only if they are executed in writing and signed by both Parties.
10.5 All annexes to this Agreement shall form its integral part.
10.6 The services under this Agreement may be performed in any country of the world, but the Contractor and the Customer shall be legally liable in accordance with the Russian legislation.
10.7. All disputes on fulfilment of the Contract conditions between the parties shall be settled in the claim procedure. In case the parties fail to come to a mutual agreement, the disputes shall be resolved in the arbitration court at the location of the Customer.
11. Term of validity of the Offer and procedure of its change
11.1 This Offer comes into force from the moment of publication on the Site in the Internet and is valid until the moment of withdrawal / modification of the Offer by the Contractor.
11.2. . The Contractor reserves the right to amend the terms and conditions of the Offer Agreement at any time without prior notice to the Customer. Unless otherwise specifically agreed, all amendments and additions to the Offer Agreement shall come into force from the moment of publication on the Website.
12. Contractor's requisites
OOO "CARBONIT"
INN 5032331004
KPP 503201001
OGRN 1215000072935
Legal address 143041, Moscow region, Odintsovsky district
Heads Nalivaiko Elena Yurievna (General Director)
Bank JSC "ALFA-BANK".
Cor. account 30101810200000000593.
BIC 044525593.
Account number 40702810602820003389